Southside Park Pool Renovation

…specified above shall in any manner be construed to constitute a release of any such liabilities nor a waiver of the City’s right to withhold payment for such liabilities. 16. INDEMNITY AND HOLD HARMLESS A. Contractor shall defend, hold harmless and indemnify the City, its officers, employees, and agents, and each and every one of them, from and against any and all actions, damages, costs, liabil

…City’s right to withhold payment for such liabilities. 16. INDEMNITY AND HOLD HARMLESS A. Contractor shall defend, hold harmless and indemnify the City, its officers, employees, and agents, and each and every one of them, from and against any and all actions, damages, costs, liabilities, claims, demands, losses, judgments, penalties, costs and expenses of every type and description, whether arisi

…www.faa.gov. 8. FG - Federal Government Publications; www.gpo.gov/fdsys. 9. GSA - General Services Administration; www.gsa.gov. 10. HUD - Department of Housing and Urban Development; www.hud.gov. 11. LBL - Lawrence Berkeley National Laboratory; Environmental Energy Technologies Division; www.eetd.lbl.gov. 12. OSHA - Occupational Safety & Health Administration; www.osha.gov. 13. SD - Department of

…ne signed original copies of each Application for Payment to Owners Representative by an electronic method ensuring receipt. Include waivers of lien and similar attachments. 1. Transmit each copy with a transmittal form listing attachments and recording appropriate information about application. G. Waivers of Liens: With each Application for Payment, submit waivers of lien from subcontractors, su

…ately on the dateO onfe t hTeh Nouotsiacne dto D Porlolacerse d($. A1t,0ta0c0h)e d is a sample of a Notice to Proceed. The amount of liquidated damages to be paid by the Contractor for failure to complete the work by the completion date (as extended, if applicable) shall be By signing, it is also understoofodr t ehaacth a clal lleanbdoarr day, ccoonmtipnluiainngc eto r tehqeu tiirmeem aetn wtsh i