Source scope cues include: City of Sacramento; CITY OF SACRAMENTO Sealed Proposals; bid security of at least 10% of the sum the Bid Proposal. The City reserves the right to reject proposals or to waive any error or omission in any Bid Proposal received. Si; planetbids.com/portal/portal; bond requirements of the Contractor. 4. The work performed or the materials/equipment/supplies provided by the listed LBE are unsatisfactory or are not in accordance with the pl...; New City Hall, located at 915 I Street, 5th Floor, Mayor’s Reception Desk, up to the hour of 2:00 p.; an alteration, demolition, repair, and maintenance project of $15,000 or less.; employee located in the City or unincorporated county of Sacramento.; warranty period without expense or charge of any nature whatsoever to City.; demand all costs and expense of such repair.; such defect, and Contractor shall pay to City on demand all costs and expense of such repair.; otherwise ceases to be insured as required herein.; 05 Proof of Compliance with Contract .; 10 Unsuitable Material, Removal and Replacement .; Utilities, 1395 35th Ave, Sacramento, California, 95822, phone (916) 808-1451.; documents or other satisfactory proofs as to his compliance with such requirements.; gutter replacement shall coincide with sidewalk panel being replaced.; CCTV inspections; print outs of reports and the unmodified PACP database..
Free RFP preview
Bid/no-bid recommendation
BID WITH CAUTION
Source scope cues include: City of Sacramento; CITY OF SACRAMENTO Sealed Proposals; bid security of at least 10% of the sum the Bid Proposal. The City reserves the right to reject proposals or to waive any error or omission in any Bid Proposal received. Si; planetbids.com/portal/portal; bond requirements of the Contractor. 4. The work performed or the materials/equipment/supplies provided by the listed LBE are unsatisfactory or are not in accordance with the pl...; New City Hall, located at 915 I Street, 5th Floor, Mayor’s Reception Desk, up to the hour of 2:00 p.; an alteration, demolition, repair, and maintenance project of $15,000 or less.; employee located in the City or unincorporated county of Sacramento.; warranty period without expense or charge of any nature whatsoever to City.; demand all costs and expense of such repair.; such defect, and Contractor shall pay to City on demand all costs and expense of such repair.; otherwise ceases to be insured as required herein.; 05 Proof of Compliance with Contract .; 10 Unsuitable Material, Removal and Replacement .; Utilities, 1395 35th Ave, Sacramento, California, 95822, phone (916) 808-1451.; documents or other satisfactory proofs as to his compliance with such requirements.; gutter replacement shall coincide with sidewalk panel being replaced.; CCTV inspections; print outs of reports and the unmodified PACP database..
2015-03-09
15 red flags detected including Back-Charge / Setoff Rights.
Locked analysis
…arge all such liabilities of Contractor, Contractor shall continue to remain liable to City until all such liabilities are satisfied in full. No failure by City to withhold any payment as specified above shall in any manner be construed to constitute a release of any such liabilities nor a waiver of the City’s right to withhold payment for such liabilities. Form approved by City Attorney 1-11-17
16. INDEMNITY AND HOLD HARMLESS A. Contractor shall defend, hold harmless and indemnify the City, its officers, employees, and agents, and each and every one of them, from and against any and all actions, damages, costs, liabilities, claims, demands, losses, judgments, penalties, costs and expenses of every type and description, whether arising on or off the site of the Work, including, but not li
…ive mains shall be removed such that no protrusions remain. The method of abandoning the mains depends on the type of existing pipe. Asbestos- cement, steel, and cast iron pipe shall be plugged with two (2) feet of concrete. Steel pipe shall be abandoned by welding 1/4-inch thick steel plate on cut ends. Use of a restrained MJ cap to abandon steel main, rather than welding, in the event that valv
…f the work within a period of Thirty Five (35) working days commencing on the date specified in the Notice to Proceed. The amount of liquidated damages to be paid by the Contractor for failure to complete the work by the completion date (as extended, if applicable) shall be Seven Hundred Dollars ($700) for each calendar day, continuing to the time at which the work is completed. Such amount is th
…ed LBE fails to perform its contractual obligations. 5. It would be in the best interest of the City. C. Subcontractor Substitution: No substitution of a LBE subcontractor shall be made at any time without compliance with the Subletting and Subcontracting Fair Practices Act. If a LBE subcontractor is unable to perform successfully and is to be replaced, the Contractor shall make reasonable effort
Locked analysis
| Item | Due |
|---|---|
| Project Award | 2015-03-09 |
| (i) This section shall remain in effect only until | 2020-01-01 |
Locked analysis
Locked workspace
Open the full workspace to review evidence, generate response documents, and work from the analyzed checklist.
Email any RFP PDF to rfp@mail.bidterms.com and get a full analysis back in under 5 minutes, free.
Or start your free trial →Related public analyses
DEPT OF DEFENSE.DEPT OF THE AIR FORCE.AIR COMBAT COMMAND.FA4686 9 CONS PK
Riverside, CA (city)
DEPT OF DEFENSE.DEPT OF THE NAVY.NAVSUP.NAVSUP OTHER HCA.CNIC.COMMANDER NAVY INSTALLATIONS CMD
DEPT OF DEFENSE.DEPT OF THE AIR FORCE.AIR MOBILITY COMMAND.FA4427 60 CONS LGC