Source scope cues include: NUMBER RFP-HD-18-007 CONTRACTOR SERVICES RESTORE THE INFILTRATION RATE 7™ STREET BASIN AND 8™ STREET BASIN; sealed envelope with all original; BID BOND 3-15 REQUEST FOR PROPOSAL: RFP-HD-18-007 TOC-1 SECTION 4 - TECHNICAL SPECIFICATIONS PROJECT INTRODUCTION 4-1 PURPOSE 4-1 SCOPE OF WORK 4-1 TaskA 4-3 Task B; sealed proposal; judgment or carelessness in the interpretation of the scope of work.; Payment discount proposed, in exchange for expedited invoice payment.; expedited payment of any or all invoices.; Business License number issued by the City where the Offeror's principal place of business is located.; TYPE OF SERVICES PROVIDED (Note: Please attach a “typical” invoice, for the services provided.; removal shall not be relocated to any onsite area outside of the basin.; manager in digital format either CD, or USB flash drive.; Task D: Ripping and Track-walking and Channel Washout Repair.; The 7" Street Basin is located just west of Grove Avenue and south of 7‘ Street.; Bernardino County and San Bernardino County Flood Control District as additional insured’s.; No additional permits are required from this entity.; Empire Utilities Agency for the contracted and fully executed work.; Project Manager within thirty (30) days following receipt of the invoice.; 6075 Kimball Avenue, Building A, Chino, California; 6075 Kimball Avenue, Bldg.; 6075 Kimball Avenue, Building A.
Free RFP preview
Bid/no-bid recommendation
BID WITH CAUTION
Source scope cues include: NUMBER RFP-HD-18-007 CONTRACTOR SERVICES RESTORE THE INFILTRATION RATE 7™ STREET BASIN AND 8™ STREET BASIN; sealed envelope with all original; BID BOND 3-15 REQUEST FOR PROPOSAL: RFP-HD-18-007 TOC-1 SECTION 4 - TECHNICAL SPECIFICATIONS PROJECT INTRODUCTION 4-1 PURPOSE 4-1 SCOPE OF WORK 4-1 TaskA 4-3 Task B; sealed proposal; judgment or carelessness in the interpretation of the scope of work.; Payment discount proposed, in exchange for expedited invoice payment.; expedited payment of any or all invoices.; Business License number issued by the City where the Offeror's principal place of business is located.; TYPE OF SERVICES PROVIDED (Note: Please attach a “typical” invoice, for the services provided.; removal shall not be relocated to any onsite area outside of the basin.; manager in digital format either CD, or USB flash drive.; Task D: Ripping and Track-walking and Channel Washout Repair.; The 7" Street Basin is located just west of Grove Avenue and south of 7‘ Street.; Bernardino County and San Bernardino County Flood Control District as additional insured’s.; No additional permits are required from this entity.; Empire Utilities Agency for the contracted and fully executed work.; Project Manager within thirty (30) days following receipt of the invoice.; 6075 Kimball Avenue, Building A, Chino, California; 6075 Kimball Avenue, Bldg.; 6075 Kimball Avenue, Building A.
Not listed in the public preview.
14 red flags detected including Broad Indemnification.
Locked analysis
…performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless, Owner and Engineer, their officers, agents, and employees as therein stipulated, then this obligation shall become null and void; otherwise it shall be and remain in full force and virtue and Principal and Surety, in the event suit is br
…, Equal Opportunity, Dispute Resolution (Arbitration), Prevailing Wages, Worker's Legal Status, Fitness for Duty, Governing Law, and Liquidated Damages.” Alll Contractors intending to submit proposals to perform the work described under this Specification shall fully inform themselves of the provisions of the Agency’s Typical Contract for the performance of Maintenance type work before making the
…Labor Code Sections 1810 to 1817, Liens, Indemnification, Conflict of Interest, Equal Opportunity, Dispute Resolution (Arbitration), Prevailing Wages, Worker's Legal Status, Fitness for Duty, Governing Law, and Liquidated Damages.” Alll Contractors intending to submit proposals to perform the work described under this Specification shall fully inform themselves of the provisions of the Agency’s T
SUMMARY FEE SCHEDULE "A" 3-1 FEE INCLUSION STATEMENT 3-1 PROPOSED FEE FOR CONTRACTOR’S SERVICES 3-1 EXPEDITED PAYMENT DISCOUNT 3-2 PROPOSAL SIGNATURE - 3-2 OFFEROR IDENTIFICATION 3-3 REFERENCES AND SUBCONTRACTORS 3-4 WORKERS' COMPENSATION CERTIFICATE 3-5 NON-COLLUSION AFFIDAVIT 3-6 WAIVER/RELEASE OF LIABILITY 3-7 EXCEPTION FORM 3-8 PERFORMANCE BOND 3-9 PAYMENT BOND 3-12 BID BOND 3-15
1. General Liability: $1,000,000 combined single limit per occurrence for bodily injury, personal injury and property damage. Coverage shall be at least as broad as Insurance Services Office form number GL 0001-87 covering Comprehensive General Liability. If Commercial General Liability Insurance or other form with a general aggregate limit is used, either the general aggregate limit shall apply s
Locked analysis
| Item | Due |
|---|---|
| No deadlines detected. | |
Locked analysis
Locked workspace
Open the full workspace to review evidence, generate response documents, and work from the analyzed checklist.
Email any RFP PDF to rfp@mail.bidterms.com and get a full analysis back in under 5 minutes, free.
Or start your free trial →Related public analyses
DEPT OF DEFENSE.DEPT OF THE AIR FORCE.AIR COMBAT COMMAND.FA4686 9 CONS PK
Riverside, CA (city)
DEPT OF DEFENSE.DEPT OF THE NAVY.NAVSUP.NAVSUP OTHER HCA.CNIC.COMMANDER NAVY INSTALLATIONS CMD
DEPT OF DEFENSE.DEPT OF THE AIR FORCE.AIR MOBILITY COMMAND.FA4427 60 CONS LGC