Source scope cues include: CITY OF SACRAMENTO Sealed Proposals; City of Sacramento; bid security of at least 10% of the sum the Bid Proposal. The City reserves the right to reject proposals or to waive any error or omission in any Bid Proposal received. Si; planetbids.com/portal/portal; New City Hall, located at 915 I Street, 5th Floor, Mayor’s Reception Desk, up to the hour of 2:00 p.; an alteration, demolition, repair, and maintenance project of $15,000 or less.; warranty period without expense or charge of any nature whatsoever to City.; demand all costs and expense of such repair.; such defect, and Contractor shall pay to City on demand all costs and expense of such repair.; otherwise ceases to be insured as required herein.; 05 Proof of Compliance with Contract .; satisfactory proofs as to his compliance with such requirements.; b) Damage to existing water main and water service connections and methods of repair.; c) Damage to other existing utilities.; Placement shall be on barricades and located at each end of the work area.; Access for emergency vehicles shall always be available.; gutter replacement shall coincide with sidewalk panel being replaced.; pools, sidewalks, walls, irrigation systems and other underground utilities..
Free RFP preview
Bid/no-bid recommendation
BID WITH CAUTION
Source scope cues include: CITY OF SACRAMENTO Sealed Proposals; City of Sacramento; bid security of at least 10% of the sum the Bid Proposal. The City reserves the right to reject proposals or to waive any error or omission in any Bid Proposal received. Si; planetbids.com/portal/portal; New City Hall, located at 915 I Street, 5th Floor, Mayor’s Reception Desk, up to the hour of 2:00 p.; an alteration, demolition, repair, and maintenance project of $15,000 or less.; warranty period without expense or charge of any nature whatsoever to City.; demand all costs and expense of such repair.; such defect, and Contractor shall pay to City on demand all costs and expense of such repair.; otherwise ceases to be insured as required herein.; 05 Proof of Compliance with Contract .; satisfactory proofs as to his compliance with such requirements.; b) Damage to existing water main and water service connections and methods of repair.; c) Damage to other existing utilities.; Placement shall be on barricades and located at each end of the work area.; Access for emergency vehicles shall always be available.; gutter replacement shall coincide with sidewalk panel being replaced.; pools, sidewalks, walls, irrigation systems and other underground utilities..
2018-12-21
14 red flags detected including Back-Charge / Setoff Rights.
Locked analysis
…arge all such liabilities of Contractor, Contractor shall continue to remain liable to City until all such liabilities are satisfied in full. No failure by City to withhold any payment as specified above shall in any manner be construed to constitute a release of any such liabilities nor a waiver of the City’s right to withhold payment for such liabilities. Form approved by City Attorney 1-11-17
16. INDEMNITY AND HOLD HARMLESS A. Contractor shall defend, hold harmless and indemnify the City, its officers, employees, and agents, and each and every one of them, from and against any and all actions, damages, costs, liabilities, claims, demands, losses, judgments, penalties, costs and expenses of every type and description, whether arising on or off the site of the Work, including, but not li
…uth Land Park Drive, along the rear fence line. The pipe alignment extends beneath an oak tree and next to an active 8-inch diameter asbestos cement water main. USA markings indicate the water and sewer mains are less than two feet apart. Previous inspections located a large fracture at a joint approximately six feet downstream of manhole 119RR13. There is a pond with water fall near manhole 119R
…n completion of the work within a period of 45 working days commencing on the date specified in the Notice to Proceed. The amount of liquidated damages to be paid by the Contractor for failure to complete the work by the completion date (as extended, if applicable) shall be Six Hundred Dollars ($600.00) for each calendar day, continuing to the time at which the work is completed. Such amount is t
…sion of Labor Compliance Reports, which became effective May 1, 2007. The contractor and every lower-tier subcontractor shall submit certified payrolls and labor compliance documentation electronically at the discretion of and in the manner specified by the City of Sacramento. Electronic submittal is via a web-based system, accessed on the World Wide Web by a web browser. Each contractor and subc
Locked analysis
| Item | Due |
|---|---|
| Project Award | 2018-12-21 |
| (i) This section shall remain in effect only until | 2020-01-01 |
Locked analysis
Locked workspace
Open the full workspace to review evidence, generate response documents, and work from the analyzed checklist.
Email any RFP PDF to rfp@mail.bidterms.com and get a full analysis back in under 5 minutes, free.
Or start your free trial →Related public analyses
DEPT OF DEFENSE.DEPT OF THE AIR FORCE.AIR COMBAT COMMAND.FA4686 9 CONS PK
Riverside, CA (city)
DEPT OF DEFENSE.DEPT OF THE NAVY.NAVSUP.NAVSUP OTHER HCA.CNIC.COMMANDER NAVY INSTALLATIONS CMD
DEPT OF DEFENSE.DEPT OF THE AIR FORCE.AIR MOBILITY COMMAND.FA4427 60 CONS LGC