Source scope cues include: CITY OF SACRAMENTO Public; CITY OF SACRAMENTO Bid No; Bid Security. Bid Security is: [ ] Required [ X ] Not Required If required, bid security approved by the City must accompany the bid, in the amount of ___ % of the total am; planetbids.com/portal/portal; sealed proposal; Bids must be submitted in a sealed envelope or package.; The City assumes that all invoices are paid within the discount terms (all discounts are taken).; Emergency/Declared Disaster Requirements.; under the same terms and conditions that apply during non-emergency/disaster conditions.; located in the City or unincorporated county of Sacramento.; related items located throughout the City of Sacramento.; Side Forms and Headers, and Section 24 – Curb, Gutter, Sidewalks, and Gutter Drains.; Doweling is required on all sidewalk, curb, and gutter projects.; burden of proof of an incorrect billing shall be on the Contractor.; completion of the excavation activities prior to the invoice being submitted.; Only emergency repairs will be permitted during this holiday period.; damage through the excavation or replacement work of the project.; be cemented flush with the surface of the concrete gutter, and/or curb..
Free RFP preview
Bid/no-bid recommendation
BID WITH CAUTION
Source scope cues include: CITY OF SACRAMENTO Public; CITY OF SACRAMENTO Bid No; Bid Security. Bid Security is: [ ] Required [ X ] Not Required If required, bid security approved by the City must accompany the bid, in the amount of ___ % of the total am; planetbids.com/portal/portal; sealed proposal; Bids must be submitted in a sealed envelope or package.; The City assumes that all invoices are paid within the discount terms (all discounts are taken).; Emergency/Declared Disaster Requirements.; under the same terms and conditions that apply during non-emergency/disaster conditions.; located in the City or unincorporated county of Sacramento.; related items located throughout the City of Sacramento.; Side Forms and Headers, and Section 24 – Curb, Gutter, Sidewalks, and Gutter Drains.; Doweling is required on all sidewalk, curb, and gutter projects.; burden of proof of an incorrect billing shall be on the Contractor.; completion of the excavation activities prior to the invoice being submitted.; Only emergency repairs will be permitted during this holiday period.; damage through the excavation or replacement work of the project.; be cemented flush with the surface of the concrete gutter, and/or curb..
2014-06-20
12 red flags detected including Broad Indemnification.
Locked analysis
…erformed at the time and in the manner therein specified, and in all respects according to their true intent and meanings, and shall indemnify and save harmless the City, its officers, employees and agents, as therein provided, then this obligation shall be null and void; otherwise shall be and remain in full force and effect. This obligation shall remain in full force and effect until (1) the da
…ernment construction contracts in Sacramento County within the last five years: Within those five years, has your firm been assessed liquidated damages on three or more government construction contracts in Sacramento County for failure to complete contract work on time? NOTE: If there is a pending administrative or court action challenging the assessment of liquidated damages on a government cont
…ices, Respondents must identify all taxable materials on a separate line item(s) from services to receive this price preference. 14. Mandatory Pre-Bid Conference. If a mandatory Pre-Bid Conference is indicated on the cover of this Invitation for Bid, all bidders are required to attend the conference. Failure to attend this conference will result in rejection of your bid. If a mandatory Pre-Bid Co
…2014, and became effective immediately, made several significant changes to laws pertaining to the administration and enforcement of prevailing wage requirements by the Department of Industrial Relations (DIR). Among other things, SB 854 established a new public works contractor registration program to replace prior Compliance Monitoring Unit (CMU) and Labor Compliance Program (LCP) requirements
…ration and enforcement of public works requirements: Requirements to use CMU or specified alternative (labor compliance program or project labor agreement) for state bond-funded and other specified projects have been eliminated and replaced by requirements that apply to all public works projects (as defined under the Labor Code). Awarding bodies are now required to submit PWC-100 (contract aw
Locked analysis
| Item | Due |
|---|---|
| awarding agencies for CMU services provided through | 2014-06-20 |
| now limited to: (1) public works projects awarded prior to | 2012-01-01 |
Locked analysis
Locked workspace
Open the full workspace to review evidence, generate response documents, and work from the analyzed checklist.
Email any RFP PDF to rfp@mail.bidterms.com and get a full analysis back in under 5 minutes, free.
Or start your free trial →Related public analyses
DEPT OF DEFENSE.DEPT OF THE AIR FORCE.AIR COMBAT COMMAND.FA4686 9 CONS PK
Riverside, CA (city)
DEPT OF DEFENSE.DEPT OF THE NAVY.NAVSUP.NAVSUP OTHER HCA.CNIC.COMMANDER NAVY INSTALLATIONS CMD
DEPT OF DEFENSE.DEPT OF THE AIR FORCE.AIR MOBILITY COMMAND.FA4427 60 CONS LGC